Last updated: January 1, 2024
By accessing and using the DecoreWindows website and services, you accept and agree to be bound by the terms and provision of this agreement. If you do not agree to abide by the above, please do not use this service.
DecoreWindows provides custom window treatments, home furnishing design, consultation, manufacturing, and installation services. All services are subject to availability and may vary by location within California.
Free in-home consultations are provided within our service areas. Estimates provided are valid for 30 days from the date of issue. Final pricing may vary based on actual measurements and material selections.
All orders require a signed contract and deposit. Payment terms will be specified in your contract. We accept cash, check, and major credit cards. Custom orders are non-refundable once manufacturing has begun.
Manufacturing times vary by product and are estimates only. We will provide expected delivery dates but are not liable for delays due to circumstances beyond our control. Installation will be scheduled upon delivery of products.
Professional installation is included with most products. Customer must provide clear access to installation areas. Any damage to existing structures during installation will be repaired at our expense, subject to reasonable limitations.
We provide comprehensive warranties on our products and installation. Warranty terms vary by product and will be specified in your contract. Warranties do not cover damage due to misuse, normal wear and tear, or acts of nature.
DecoreWindows' liability is limited to the cost of the products and services provided. We are not liable for consequential, incidental, or special damages. Our total liability shall not exceed the amount paid for our services.
All content on this website, including designs, text, graphics, and logos, is the property of DecoreWindows and is protected by copyright and trademark laws. Unauthorized use is prohibited.
Your privacy is important to us. Please review our Privacy Policy, which also governs your use of our services, to understand our practices.
These terms and conditions are governed by and construed in accordance with the laws of the State of California. Any disputes shall be resolved in the courts of California.
DecoreWindows reserves the right to modify these terms at any time. Changes will be posted on this page with an updated revision date. Continued use of our services constitutes acceptance of modified terms.
If you have any questions about these Terms and Conditions, please contact us at:
DecoreWindows
123 Design Avenue
San Francisco, CA 94102
Phone: (626) 355-7030
Email: info@decorewindows.com